We previously blogged about the hotly contested dispute between AECOM and FlatIron involving the I-70 construction project outside of Denver. After an 18-day trial, the jury returned a verdict last month for plaintiff AECOM on its breach of contract claim. Interestingly, the size of the jury’s verdict, roughly $5 million, was consistent with FlatIron’s attempted
The Second Circuit Court of Appeals recently applied a no-damages-for-delay provision to affirm the dismissal of a demolition contractor’s breach of contract claims. The project involved reconstructing and raising the Bayonne Bridge between Staten Island and New Jersey. The Port Authority awarded the general contract on the $1.29 billion project to the joint venture Skanska
A California federal court ruled last week that a surety can enforce an arbitration clause in a contract to which it is not a party. The dispute involves performance and payment bond claims brought by solar contractor Swinerton Builders, Inc. Swinerton brought the claims in California federal court against Argonaut Insurance, the surety of a
The words breach and default are often used interchangeably to indicate that somebody hasn’t done what they were legally required to do. According to Black’s Law Dictionary, the words do appear somewhat interchangeable. Black’s defines breach as “a violation or infraction of a law, obligation, or agreement, especially of an official duty or a legal
Construction contracts often include clauses that purport to limit the liability of one or both parties. This includes clauses that completely prohibit any claims for certain types of damages such as lost profits and other consequential damages, extended overhead or other “delay” damages, and exemplary/punitive damages. Contracting parties may also include clauses that purport to cap liability
The court in AECOM v. Flatiron is back at it issuing additional evidentiary rulings as the parties head to trial later this month. These latest rulings highlight the risk of seeking the same damages from multiple parties, sometimes referred to as “fighting on two fronts.” As you may recall, AECOM v. Flatiron involves claims by
A Colorado federal court will allow a contractor to prove up more than $250 million in damages using the modified total cost method (see AECOM Technical Services v. Flatiron AECOM, LLC, Case No. 19-CV-2811, 2024 WL 22640 (D. Co. Jan. 2, 2024)). The AECOM v. Flatiron case involves a Colorado DOT project to add
A Utah federal court recently held that when negotiating a pass-through settlement agreement, a contractor has a duty to disclose information to its subcontractor regarding the viability of the claims to be passed through. See Ludvik v. Vanderlande, 2023 WL 8789379 (D. Utah, Dec. 19, 2023). If it breaches that duty, the contractor may
Recently, the Oregon Court of Appeals reinstated a contractor’s mechanics lien claim notwithstanding the owner’s offer of payment because the offer was conditioned on the contractor signing a broad lien waiver that would have released other claims. See, Development Northwest, Inc. v. Zhiryada, 329 Or. App. 427 (December 6, 2023).
After completing its work, the
Back in April we examined the court’s decision in Boldt v. Black & Veatch, which dismissed a subcontractor’s counterclaim for wrongful termination on a 60-turbine wind farm project. As you may recall, the subcontractor hired to erect the turbines alleged that it was wrongfully terminated for delays that were not its fault but were